Potential Supervision Consultant Contract Disputes Due to Extension of Contractor Time in DKI Jakarta Regional Government Project Based on Fidic White Book
DOI:
https://doi.org/10.32832/astonjadro.v13i1.14772Keywords:
potential disputes; contract supervising consultants; contractor time extension; DKI Jakarta local government project.Abstract
DKI Jakarta is a province in Indonesia that has the most significant regional budget (APBD). This has led to numerous infrastructure development projects funded by the regional budget in Jakarta. Most projects in Jakarta follow a traditional document tendering process, where procurement starts with the engagement of planning consultants to design a project. After the planning documents are completed, contractor and supervision consultant services are procured concurrently. This research aims to identify the factors that result in non-extension and non-payment of supervising consultants and to determine the potential dominant disputes in supervising consultant contracts due to contractor time extension addendums, particularly in projects within the regional government environment of DKI Jakarta. The aim is to minimize the impact of such issues in the future. This research is a combined study with a sequential form. The population of this research consists of building construction projects in the province of DKI Jakarta. The sample for this research is a sports arena construction project. The respondents in this study are the project owners and the supervising consultants associated with the research project. The data will be processed using a rating evaluation method, allowing for the relative comparison of the predetermined variable categories with each other. The provisions should be based on fairness between the contracting parties. The research findings indicate that supervising consultants are entitled to time extensions and additional fees for supervision during the extended period, due to the contractor's extension of the physical implementation time based on technical considerations. The feasibility of the extension proposal is assessed through research, and the results are documented in an addendum to the contract.
References
Adab, Otti Ilham Khair Penerbit. (2023). Kebijakan dan Sanksi Dalam Peraturan Presiden Nomor 12 Tahun 2021 Tentang Perubahan Atas Peraturan Presiden Nomor 16 Tahun 2018 Tentang Pengadaan Barang/Jasa Pemerintah. Penerbit Adab.
Asnuddin, Setyadi, Tjakra, Jermias, & Sibi, Mochtar. (2018). Penerapan Manajemen Konstruksi Pada Tahap Controlling Proyek.(Studi Kasus: Bangunan Laboratorium Fakultas Teknik Universitas Sam Ratulangi Manado). Jurnal Sipil Statik, 6(11).
Hansen, S. (2017). Quantity Surveying: Pengantar Manajemen Biaya dan Kontrak Konstruksi. Gramedia Pustaka Utama.
Hardjomuljadi, Sarwono. (2014). Analisis “Extension of Time” dan Dampaknya pada Kontrak Konstruksi (FIDIC Conditions of Contract MDB Harmonised Edition). Konstruksia, 5(2).
Hardjomuljadi, Sarwono. (2020). Use of dispute avoidance and adjudication boards. Journal of Legal Affairs and Dispute Resolution in Engineering and Construction, 12(4), 03720004.
Hutasoit, Wesley Liano. (2019). Analisa pemindahan ibukota negara. DEDIKASI: Jurnal Ilmiah Sosial, Hukum, Budaya, 39(2), 108–128.
Kharina, Fitri Nur, & Sambowo, Kusno Adi. (2019). Analisis Keterlambatan Proyek Serta Dampaknya Terhadap Biaya Dan Waktu Pelaksanaan Proyek. Jurnal Infrastruktur, 5(1), 13–19.
Maulana, Aceng. (2016). Faktor Penyebab Terjadinya Contract Change Order (CCO) dan Pengaruhnya Terhadap Pelaksanaan Proyek Konstruksi Pembangunan Bendung. Jurnal Infrastruktur, 2(2), 40–51.
Nasrul, Nasrul, & Mulyadi, Beni. (2019). Tinjauan Addendum Waktu Pelaksanaan Proyek Pembangunan Jembatan Kampung Baru Nan Xx Kota Padang. Rang Teknik Journal, 2(2).
Novita, Syawalia, & Yusri, Yusri. (2020). Wanprestasi Kontrak Kerja Konstruksi Antara Kementerian Kelautan Dan Perikanan Dengan Pt. Putra Nanggroe Aceh (Suatu Penelitian di Proyek Pembangunan Fisik Pusat Restorasi Pembelajaran Mangrove di Simeuleu). Jurnal Ilmiah Mahasiswa Bidang Hukum Keperdataan, 4(3), 615–627.
NURAWALIAH, A. I. S. (2022). Analisis Faktor Penyebab Contract Change Order (Cco) Pada Proyek Konstruksi Gedung Gedung Di Universitas Siliwangi (Doctoral dissertation, Universitas Siliwangi).
Nurhuda, Dwi Sasongko, Sutrisno, Widarto, & Galuh, Dimas Langga Chandra. (2019). Analisis risiko keterlambatan waktu pada pelaksanaan proyek pembangunan spbu (studi kasus di kabupaten Bantul, Yogyakarta). Bangun Rekaprima: Majalah Ilmiah Pengembangan Rekayasa, Sosial Dan Humaniora, 5(2, Oktober), 19–28.
Sudarwanto, Adenk. (2013). Analisis APBD Tahun 2012. Jurnal STIE Semarang, 5(1), 132489.
Suprihanto, John, & Putri, Lana Prihanti. (2021). Manajemen Sumber Daya Manusia. UGM PRESS.
Wahyuni, Fatma Ira, Syamsyuir, Elvi, & Vitri, Gusni. (2021). ANALISA Faktor Penyebab Dan Akibat Contract Change Order Pada Proyek Kontruksi Gedung Di Kabupaten Limapuluh Kota. Ensiklopedia of Journal, 4(1), 123–130.
Downloads
Published
How to Cite
Issue
Section
License
Copyright (c) 2024 ASTONJADRO
This work is licensed under a Creative Commons Attribution-ShareAlike 4.0 International License.
Paper submitted to ASTONJADRO is the sole property of the Astonjadro Journal. Unless the author withdraws the paper because he does not want to be published in this journal. The publication rights are in the journal Astonjadro.ASTONJADRO
LICENSE
This work is licensed under a Creative Commons Attribution-ShareAlike 4.0 International License.
Based on a work at http://ejournal.uika-bogor.ac.id/index.php/ASTONJADRO
